General purchase conditions
1.1. These general purchasing conditions (GPC) apply to all business transactions of ULIKETT GmbH (from now on “ULIKETT”) with the signing contractor, in so far as not otherwise explicitly agreed in writing by the contractual parties. Agreements and/or ancillary agreements which deviate from these GPC may only be agreed upon on a case-by-case basis. These GPC shall also apply for all additional business transactions until they are amended, even if they are no longer referred to in particular.
1.2. The contractor agrees that in the event that the contractor uses General Business and/ or Delivery Conditions, even if they remain un-objected, the conditions at hand shall apply. Action by ULIKETT to fulfil contractual obligations and/or silence by ULIKETT shall not be deemed as an approval of the conditions that deviate from the conditions under this contract.
1.3. The following regulations regarding the purchasing of goods apply accordingly also to the use of (work) services. They apply in the same manner to main or supplementary services.
1.4. This collaboration does not establish any kind of relationship under company-law.
1.5. Amendments and modifications of these GPC must be made in writing; this shall also apply to ancillary agreements and subsequent contractual modifications as well as renunciation of the written form requirement. Provided that these GPC stipulate the written form, an e-mail or fax shall generally comply therewith, whereby it is incumbent upon the sender to have proof of receipt of such e-mail or fax.
2. Offer, Orders
2.1. Offers and cost estimates have to be submitted free of charge. ULIKETT reserves the right to demand a detailed cost breakdown.
2.2. After the contractor has submitted an offer, he is obligated to uphold the therein stated declarations towards ULIKETT for 60 days. The order is considered timely if it is sent within the stated time period.
2.3. Only orders placed in writing by ULIKETT are legally binding. The order can be placed by stating an order number by ULIKETT. Such shall be referenced by the contractor on all documents relating to the order.
2.4. If time periods are calculated based on the order date, the date that is stated on the written order shall apply if in doubt.
2.5. ULIKETT is entitled to correct at any time obvious errors, such as typing or calculation errors, in orders, offer acceptances and similar documents.
3. Order Confirmation/ Conclusion of Contract
3.1. The contractor shall confirm to ULIKETT the acceptance of the order without delay - by stating in particular the goods, price, and delivery time - in writing by way of an order confirmation. The contract is deemed concluded at the time of receipt of the order confirmation. In case of orders received by fax, a copy of the fax order marked ‘received’ shall be sent back to ULIKETT either by mail or by fax. In case of orders received by e-mail, the order shall be confirmed through an answer via e-mail including the e-mail sent by ULIKETT.
3.2. In the event that the written order confirmation is not received within 3 working days, ULIKETT reserves the right to withdraw the order. If the contractor undertakes delivery performances that are evident to ULIKETT within this time period without having confirmed the order, the latter is deemed accepted without reservations.
3.3. Subsequent changes and additions of the contract require the written confirmation by ULIKETT to be valid. Delivery Conditions of the contractor are only binding on ULIKETT if they are accepted by ULIKETT separately and in writing.
3.4. To the extent of what is reasonable to be expected of the contractor, ULIKETT is entitled to require changes of the contract with regard to execution and quantity after the conclusion of the contract, insofar as this is necessary due to special operational reasons and such changes are customary. In so doing, effects on the delivery date and potential increases or decreases of costs shall be regulated appropriately and in mutual agreement. However, increases in prices and extensions of delivery dates are only acceptable if the change actually results in real and proven cost increases or delivery extensions and if the contractor advises ULIKETT thereof in writing immediately after the order has been changed.
3.5. The change of suppliers of raw materials or of the production technology for the purpose of the order execution and the change and transfer of the production or disposal facilities as well as the redevelopment of products delivered to ULIKETT requires the expressed written consent by ULIKETT.
4.1. The order prices are fixed net prices free of charge to the place of receipt and include transportation, insurance, packaging, unloading and, if applicable, installation. If fees, taxes, customs, or other fees apply in connection with the delivery, those shall be borne by the contractor insofar as permitted under the law.
4.2. Subsequent price increases are not accepted; price increases pursuant to Paragraph 3.4 remain unaffected.
5.1. The agreed upon delivery date shall be binding. It is deemed as complied with when the delivery or performance has been provided in its entirety by the agreed upon date at the agreed upon location.
5.2. If no calendar date has been determined as a delivery date, but if a delivery time period has been agreed upon, the period shall start to run with the conclusion of the agreement in accordance with Paragraph 3.1.
5.3. The contractor has to submit in a timely fashion such proper documentation as ULIKETT may require in order to obtain official permits as well as all other permits from third parties which are required for the execution or the operation of facilities. The same shall apply for documentation that is required for an exemption or preferential treatment of taxes, customs, or other fees.
5.4. If the contractor foresees difficulties regarding the timely delivery, he has to inform ULIKETT without delay in writing stating a possible delivery date. In case of acceptance by ULIKETT of this new delivery date, claims for damage due to the delayed delivery as well as claims based on a contractual penalty agreed upon for the event of default remain unaffected.
5.5. Disputes do not entitle the contractor to withhold or cease deliveries and/or services that are due.
5.6. If the contractor defaults on a delivery, and, in the event of an agreed upon partial delivery, on a partial delivery regardless of the reason except for events of force majeure in accordance with Paragraph 6, ULIKETT is entitled to withdraw from the entire contract after having granted an appropriate grace period.
5.7. In any case, the contractor has to reimburse ULIKETT for all disadvantages suffered due to this delay, regardless of fault. If ULIKETT withdraws from the contract in accordance with Paragraph 5.6, all other disadvantages suffered in connection with a covering transaction are also to be reimbursed. Insofar as partial payments already made have to be reimbursed in connection with a withdrawal, an interest rate in the amount of 9.2% above prime rate shall be deemed agreed upon starting from the effective payment date.
5.8. In the event of a delivery delay a contractual penalty shall be agreed upon separately. Exclusively for the event that no separate agreement is concluded, the contractor shall pay ULIKETT for each started week regardless of fault an amount of 2%, however no more that 10% of the price of the total order. Any damage suffered by ULIKETT which exceeds the contractual penalty shall be reimbursed as well and in such an event full satisfaction has to be achieved.
5.9. ULIKETT is not obligated to accept deliveries and services ahead of time which take place without explicit prior approval by ULIKETT. In the event of acceptance, ULIKETT reserves the right to charge costs associated herewith. Pre-term deliveries have no effect on terms of payment.
6. Force Majeure
6.1. None of the parties to the contract is liable for failure to perform their obligations under this contract if such failure is due to force majeure, specifically war, natural catastrophes, fire, flooding, explosions, earthquakes, civil unrest and official measures. To the extent that such circumstances hinder the contractor to comply with the agreed upon delivery period, the latter is extended by the duration of such circumstances. If the delivery delay exceeds the time frame of two months, ULIKETT is entitled to withdraw from the entire contract without setting an appropriate later due date.
6.2. The contractor may effectively claim force majeure if he has reported to ULIKETT and proven in writing, by fax or e-mail the case of force majeure in detail from the earliest date practicable but no later than 24 hours prior to the agreed upon delivery term. If the notification does not take place by the point in time referenced in sentence 1, then the contractor can only claim force majeure if it can be proven to have occurred within the 24-hour time frame and to have caused the delivery delay.
7. Shipping, Transfer of Risk, and Place of Fulfilment
7.1. Shipping takes place at the cost and risk of the contractor unless a different agreement has been reached in writing. The costs of transport insurance shall only be borne by ULIKETT if this has been agreed upon explicitly.
7.2. The date of delivery or timeframe for delivery stated in the order refers to the arrival of the shipment at the place of delivery referred to in the order; if no such location is stated, then the production facility of ULIKETT GmbH in A-1230 Wien (Vienna), Wiegelestraße 26 shall be deemed as the agreed place of delivery. Unless explicitly agreed upon in writing, the contractor is not entitled to make partial shipments or shipments ahead of time. If ULIKETT advises the contractor prior to shipment of the goods that it cannot issue a release for shipment, the contractor is obligated to store the goods in an appropriate manner for up to 3 months and to ship without delay only upon notification by ULIKETT to the extent that this can be deemed reasonable in the individual case. Price increases are however only accepted if with this change of the delivery date real and proven additional costs occurred in connection with the storage and if the contractor informs ULIKETT of such immediately in writing after the order has been changed.
7.3. Shipment notifications and delivery receipts are to be sent in duplicate and the shipment is to include a packing list. If plans, drawings, operational instructions or manuals, lists of parts, storage instructions or other explanations are necessary or customary for the use or maintenance of the delivery, these items shall represent an integral part of the order and are to be handed over to ULIKETT in German and upon request also in English language in 4 copies no later than at the time of delivery or completion. Otherwise the contractor is liable for any damage arising due to ignorance of these regulations.
7.4. If the required shipment documents are missing, the delivery is not accepted as a fulfilment of the order but shall be stored at the risk and at cost of the contractor.
7.5. The contractor has to ensure an appropriate packaging of the delivery according to its nature and as appropriate for transport. Damage and costs caused by failure to observe the instructions issued accordingly by ULIKETT are borne by the contractor. Loading material becomes the property of ULIKETT to the extent as to which it is not subject to specific regulations for normed loading material (standard palettes, wire boxes, etc.). g.5. Palletized goods must be delivered on Euro -pallets for safe handling. In case of non-compliance, Ulikett reserves the right to charge the costs for repacking.
7.6. Acceptance of goods takes place in accordance with the agreement. If no separate written regulations were agreed upon, the following shall apply: goods acceptance only during working days, Monday to Thursday between 8:00 a.m. and 17:30 p.m., Fridays only after prior agreement. g.6. When delivered with vans, it must be ensured by the haulier that the goods can be unloaded from the rear as well as from the side by means of an industrial truck.
7.7. Use and risks are transferred to ULIKETT effective with the acceptance of the delivery in accordance with Paragraph 8, in case of lack of agreed upon formal acceptance with acceptance of the delivery at the reception location stated by ULIKETT. The legally effective acceptance of the shipment and the transfer of risk shall take place only after inspection and acceptance by ULIKETT’s warehouse reception control. A prior confirmation of delivery receipt or payment of the invoice does not constitute an act of acceptance by ULIKETT, which means that in such a case the right of rejection of the goods remains reserved.
7.8. The place of fulfilment for delivery and payment shall be the registered office of ULIKETT. If the delivery takes place at a different location as agreed, then this location shall be the place of fulfilment.
8. Acceptance Test
8.1. Insofar as ULIKETT requests an acceptance test, this shall be agreed upon with the contractor - together with the cost of such test - explicitly in writing at the time of contract conclusion. If no deviating regulations are determined, the acceptance test at ULIKETT, or at a location to be determined by ULIKETT, shall be conducted during ULIKETT's normal hours of operation. In so doing, the standard practice of the respective industry shall set the standards for the acceptance test.
8.2. The confirmation of ULIKETT that the deliveries and services of the contractor were manufactured or were performed without defects shall serve as acceptance. For machines and deliveries that are part of a process, this includes in particular the proof of compliance with the performance values in an agreed upon or commonly performed test run.
8.3. Defects that are detected during the acceptance test are to be remedied by the contractor without delay. Until all defects are completely remedied, ULIKETT may refuse the acceptance and demand a repetition of the test.
8.4. If the acceptance does not take place within an appropriate time frame after delivery due to reasons for which the contractor is liable - specifically due to untimely remedy of existing defects - ULIKETT has the option to either demand a price reduction or, in the case of major defects, to withdraw from the contract under full reserve of potential claims for damage and without setting an appropriate grace period.
9.1. Invoices shall be mailed upon orderly delivery and service in compliance with the respectively applicable form requirements relating to sales tax, quoting order number and article number. Only those invoices which meet the above-mentioned criteria, are considered issued in accordance to the contract, will be processed by ULIKETT and cause the payment of the invoice amount to become due. As long as no deviating payment conditions have been agreed upon, payment through ULIKETT takes place by choice of ULIKETT within 30 days with 3% discount or within 90 days net, calculated respectively from the date the invoice was received or starting on the date of acceptance of delivery/service if these take place at a later time.
9.2. If down payments or partial payments have been agreed upon, these shall become due 30 days after the invoice has been received under the regulated conditions. All down payments/ partial payments take place only upon presentation of an unconditional, irrevocable bank guarantee of a renowned European credit institution which can be called without stating reasons. These requirements may change if the value of the already performed services/ deliveries exceeds the amount of the down payment or partial payment.
9.3. In the event of asserted warranty claims or other liabilities, ULIKETT reserves the right to withhold payments or to off-set such. The defence of uncertainty pursuant to § 1052 ABGB [common civil code of Austria] is excluded.
10. Retention of Title
10.1. If the contractor reserves ownership of the delivered objects, this reservation only applies until these items have been paid for insofar as ULIKETT has not already become owner of these objects due to processing, connection, or amalgamation.
10.2. Open account reservations and reservations by the corporate group are not recognized by ULIKETT.
10.3. ULIKETT shall not assign receivables from the subsequent sale of reserved goods to the contractor to secure the contractor's purchase price receivables. ULIKETT is not obligated to uphold rights of the contractor stemming from retentions of titles of any kind towards third parties.
11.1. Regardless of the legal claims by ULIKETT, the contractor is obligated to warrant each defect under the provision of the following conditions. Specifically, each deviation of the delivered goods from the ÖNORMEN [Austrian Standards] or respectively applicable international standards and guidelines as well as statements in catalogues, brochures, marketing documents, and other public statements in accordance with § 922 Section 2 ABGB is considered a defect, regardless of whether the parties to the contract referred to such in the context of the negotiations or if the respective characteristic commonly can be assumed.
11.2. The contractor warrants in particular that the use of the purchased objects does not infringe third party property rights and that, as far as machines or similar systems are involved, those are designed and manufactured in such a fashion that they comply with the respectively applicable Austrian and European safety regulations.
11.3. The contractor furthermore warrants compliance with any obligation that might apply to him in accordance with EU Regulation No. 197/2006 (REACH-V) as well as conformity of his products according to REACH.
11.4. The legal warranty periods shall apply if special warranty periods have not been agreed upon for individual delivery items. The start of the warranty period commences with the point in time of risk transfer pursuant Paragraph 7.7, in the case of defects that are not visible on the outside which are only detected during the processing and handling, at such point in time.
11.5. If a delivered part cannot be used in accordance with the agreement due to a defect in accordance with Paragraph 11.1 or 11.2, the warranty period for this part shall be extended by the duration of the disruption of the utilization. The warranty period starts anew for replaced and improved parts.
11.6. The arisen defects shall be reported to the contractor by ULIKETT. The applicability of §377 (notice of defects) and 378 (obligation to give notice of defects in the case of incorrect delivery or insufficient quantities) UGB is explicitly excluded. The statutory assumption rule of § 924 ABGB applies to all defects reported within one year from the date of delivery. If a defect exists that is covered by a warranty in accordance with Paragraph 11.1 and 11.2, the contractor shall in accordance with the option selected by ULIKETT:
a) improve the defective goods immediately on site;
b) pick up the defective goods or the defective parts for improvement, re-deliver and, if applicable, replace the defective parts and potentially install them.
c) replace the defective parts;
d) replace the defective goods;
e) to implement an appropriate price reduction.
11.7. Improvements and replacements are to be performed within the shortest possible amount of time. In the event of a delay of a necessary improvement, ULIKETT is entitled to implement such on its own or to commission a third party at the cost of the contractor.
11.8. All costs in connection with the improvement or the replacement in particular in terms of shipping, work, and material cost, customs, dismantling and installation shall be borne by the contractor.
12. Product Liability
12.1. In the event that the subject matter of the agreement contain defects in terms of the product liability law and claims are made against ULIKETT as a result, the contractor shall be obligated to indemnify ULIKETT if and insofar as the harm is caused by a defect in the subject matter of the agreement supplied by the contractor. In any case, the contractor shall reimburse ULIKETT for all expenses that arise from the defence against third-party claims, particularly all costs, expenditures, losses and other damages that arise from the infringement.
12.2. The contractor shall inform ULIKETT immediately in writing concerning potential hazards originating from the purchased items.
13. Withdrawal from the Contract
13.1. Irrespective of its other rights, ULIKETT is entitled to withdraw from the entire contract without setting a grace period,
a) If the contractor commits a material breach of the contractual provisions and, in the event that the breach can be remedied, the contractor does not do so within a reasonable extension of time together with a threat of withdrawal;
b) if insolvency, settlement, preliminary procedures or reorganization measures have been initiated over the assets of the contractor or if an insolvency procedure is rejected due to the lack of sufficient assets,
c) if the contractor assigns his company to third parties or if it is assigned to third parties based on a mortis causa legal transaction.
13.2. In the event of withdrawal, all work / deliveries / performances arising under this agreement shall be stopped and terminated. ULIKETT shall pay the contractor reasonable compensation for unfinished work / deliveries /performances already existing at the time of withdrawal. Such compensation shall not cover any lost profits or consequential damages and is limited to the value of the amount of work / delivery / performance.
13.3. No additional claims of whatever kind shall arise against ULIKETT for a justified withdrawal.
14.1. Independent of other rights, the contractual parties may terminate ongoing agreements or portions thereof upon three months’ prior notice, respectively as of 31 June or 31 December (ordinary termination).
14.2. The contractor shall not be entitled to any compensation claims whatsoever against ULIKETT in the case of ordinary termination. The contractual parties shall be obligated to comply with all commitments under these general purchasing conditions until the date of termination.
15.1. The contractor is liable for all damages caused by him, his assistants and his subcontractors and in such event full compensation shall be paid at all times. The contractor is liable specifically for all damages suffered by ULIKETT due to third-party claims for breach of contract by the contractor, regardless of legal grounds thereof.
15.2. Notwithstanding other rights held by ULIKETT under this agreement and/or on other legal grounds, the contractor shall indemnify ULIKETT from and against any and all liability, losses, costs – including attorney fees, other costs of litigation, recall costs and the like - as well as damage to property and personal injury that arise from defective performance or from breach of the agreement on the part of the contractor or its agents or subcontractors or from negligence or wilful failure to perform agreement on the part of the contractor.
15.3. ULIKETT will not acknowledge any kind of waivers of liability.
15.4. Compensation for damages arising from failure to perform may also be sought alternatively to claims for warranty.
15.5. If contractual penalties have been agreed upon for the event of breach of duty by the contractor, additional claims arising from the respective title are not excluded.
16. Assertion of Claims by the Contractor
Claims have to be filed in court within 6 months from the date when the contractor has become aware of the damage and of the damaging party, but not later than ten years from transfer of risk.
ULIKETT rejects any collection of receivables through banks or collection agencies and therefore will return any collection orders unpaid.
18. Commercial Property Rights and Copyright
18.1. The contractor warrants that his deliveries and services do not infringe patents, samples, trademarks, registered trade names, copyrights or other third-party intellectual property rights in Austria or in a country that is the destination of the deliveries to the knowledge of the contractor. Should a third party file a claim against ULIKETT based on the infringement of such rights, the contractor shall indemnify ULIKETT without burden of proof from all claims to the full extent without recourse and without compensation.
18.2. Know-how, confidential information, plans, drafts, drawings, construction documentation, catalogues, brochures, illustrations and other technical documents as well as patents, trademarks, brands and/or designs (registered or not), copyrights (including future copyrights) together with the corresponding application shall always remain the physical and intellectual property of ULIKETT and may not be reproduced or made accessible for third parties without written approval by ULIKETT. Such items may be utilized by the contractor without written approval by ULIKETT only for the purpose of execution under this contract. For all other instances the common legal regulations regarding the reproduction, imitation, competition etc. apply. The utilization of the order for marketing purposes is not allowed.
The contractor assumes the obligation to maintain the confidentiality of the processes, data and other commercial or technical information from the business area of ULIKETT which the contractor has gained knowledge about due to or as part of the cooperation, also beyond the duration of the business relationship, unless ULIKETT explicitly releases the contractor from this obligation. The contractor is also obligated to hold his employees and agents liable to maintain this privacy.
20. Contractual Penalty
In the event that the contractor violates his obligations which result from Section 18 and 19, a contractual penalty in the amount of EUR 200,000 has been set regardless of fault. A damage incurred by ULIKETT which exceeds the contractual penalty has to be reimbursed as well and in such an event full satisfaction has to be achieved.
21. Special Notices
21.1. The contractor is authorized to assign the fulfilment of the contractual obligations in full or partially to subcontractors only with written approval by ULIKETT.
21.2. Samples, models, and all documentation that was given to the contractor in connection with the order or the execution of the contract such as drawings, plans, lists, etc. remain the property of ULIKETT and have to be returned to ULIKETT without demand at the cost and risk of the contractor as soon as they are no longer needed, no later however than at the time of delivery. The contractor has no right of retention. The contractor is obligated to notify ULIKETT immediately in writing in case of commencement of bankruptcy proceedings (bankruptcy, restructuring proceedings, insolvency, etc.) and in case of rejection of an application for bankruptcy due to lack of assets to cover the costs, and to take all necessary and helpful steps to assist ULIKETT in ascertaining its separation rights.
21.3. If a provision of these general purchasing conditions be or become invalid, the effectiveness of the other provisions shall remain unchanged. The invalid provision shall be replaced by a valid provision that economically and legally comes closest to the provision to be replaced.
21.4. In as far as the conditions at hand do not specify a regulation the legal regulations shall apply exclusively.
22. Jurisdiction, Applicable Law, Contractual Language and Arbitration
22.1. For decisions regarding all disputes that may arise from the contract - including those about its existence or non-existence - the competent court shall be in Wien (Vienna), Austria. z.2. ULIKETT however also has the right to file suit in the general jurisdiction of the contractor.
22.2. Insofar as mandatory statutory provisions are not opposed thereto, Austrian law shall apply as amended with the exception of its conflict-of-law and reference rules. The application of the UN Convention on Contracts for the International Sale of Goods (CISG) is explicitly excluded.
22.3. German shall be exclusively available as the language of the agreement.
22.4. In addition, ULIKETT shall be entitled to have all disputes that arise from or in connection with this agreement definitively decided in arbitration in accordance with the rules of arbitration of the International Chamber of Commerce (ICC) by three arbitrators appointed in accordance with these rules. Such disputes are also solely subject to Austrian law with the exception of its conflict-of-law and reference rules as amended. The application of the UN Convention on Contracts for the International Sale of Goods (CISG) is explicitly excluded. The place of arbitration shall be Vienna, Austria. The language of the proceedings shall be German.